X

Cramer + Cramer General Terms and Conditions

download B2C General Terms & Conditions PDF file

download B2B General Terms & Conditions PDF file

B2C General Terms & Conditions (2025.12.06)

These General Terms and Conditions (“Terms”) apply to all sales of goods, commission of works and provision of service agreements between Cramer + Cramer Sàrl (“C+C”) and private consumers (“Customer”).
They govern the formation, content, and performance of contracts for the sale of artworks, design objects, and customised or commissioned works, whether concluded in person, by correspondence, or via C+C’s website or other electronic means.
Any general terms and conditions of the Customer are excluded, even if not expressly rejected. Individual written agreements between C+C and the Customer shall prevail over these Terms.
By placing an order, the Customer acknowledges and accepts these Terms in their current version. C+C reserves the right to amend the Terms at any time; the version in effect at the time of order placement shall apply.

Product and service descriptions, catalogues, brochures, price lists, and online listings are non-binding invitations to place an order and do not constitute legally binding offers.
The Customer’s order constitutes an offer to purchase. A contract is formed only when C+C confirms acceptance in writing (including by email) or by dispatching or delivering the goods or commissioned work.
C+C reserves the right to refuse orders, in particular for limited-editions or made-to-order works, or where payment reliability cannot be verified.
For commissioned works, the scope, concept, and specifications shall be set out in a written confirmation or project brief approved by both parties before work commences.

The Customer acknowledges that thegoods and commissioned works supplied by C+C (hereinafter the “Products”) are and should be considered as objects of art. All Products have been designed as objects of art and are sold as such. Their function is secondary to their artistic characteristics. Therefore, they should be used with extreme care, and it should not be expected of them to perform their designated or perceived function as well as items designed to be efficient in priority to being an object of art, as for example industrially made objects. The Customeris fully responsible for the use of said Products, in particular regardingthe Customer’s own or someone else’s safety, the fragility of said Products and the eventual lack of reasonable performance of Products. The Customeris responsible for transmitting above mentioned precautionary points to any possible user of Products, including if Products are lent/sold/given to third party. C+C strives to ensure that all descriptions, images, and specifications of goods or commissioned works are accurate. However, as each artwork or design object is individually created, minor variations in colour, texture, form, or artistic interpretation are possible and do not constitute defects, as further detailed below.Dimensions, weights, and other technical data are provided for guidance only unless expressly guaranteed in writing. Information provided on the website, in catalogues, or through other communications does not constitute a guarantee of characteristics unless explicitly designated as such by C+C in writing. The Customer acknowledges that each artwork or design object is individually produced and may exhibit minor variations in colour, texture, form, or artistic expression. The delicate irregularities inherent to each object reflect our dedication to preserving techniques of traditional craftsmanship. Theses irregularities form the basis of the Products’ concept and designand are therefore an inherent in the nature of the Products. Small irregularities and differences in shape, colour and surface texture between same Products are inherent to the creative or manufacturing process and cannot be considered a defect by theCustomer or a third party, and Products cannot be returned or exchanged for these reasons. Natural and hand-crafted materials such asstone, glass, ceramics and wood are particularly prone to such characteristics especially when made in an artisanal way. Products made of or including wood can also have visible knots. Shrinkage and swelling may occur in wood when the moisture content is changed. Products made of solid wood can crack with time depending on the differences in humidity and/or temperature of the spot it is placed in. Colours may fade when Product is placed in direct sunlight for a certain amount of time, regardless of the material it is made of. Slight differences between images shown online, in catalogues, or other visual representations and the delivered item, particularly in colour tone, surface finish, or proportions, are possible due to material and display factors and do not constitute defects. We do our best efforts to provide theCustomer with the best images and description of our Products but unfortunately cannot guarantee that colours and details in website images are 100% accurate representations of the product, and sizes might in some cases be approximate.
Unless otherwise agreed prices shown or quoted are in CHF (Swiss Francs)exclusive of Swiss statutory value-added tax(VAT) unless otherwise indicated. The costs of handling, packaging, shipping, insurance and other incidental costs will be charged separately and disclosed prior to order acceptance and confirmation. For cross-border transactions, the Customer bears all applicable customs duties, import and export taxes, and any administrative fees. C+C reserves the right to adjust prices in the event of changes in taxes, import duties, or other public charges that occur after the order is placed but before delivery. Such adjustments shall be communicated to the Customer in advance. For credit/debit cards not denominated in CHF, the final price will be calculated by theCustomer’s card issuer and subject to any applicable exchange rate and fees applied by theCustomer’s card issuer in accordance with their terms and conditionswhich will be borne by the Customer.
Unless otherwise agreed in writing, payment is due in full at the time the order is placed. C+C may withhold delivery until full payment has been received. If payment on account is agreed, invoices are payable within 10 days from the invoice date without deduction. In case of late payment, C+C may charge default interest at the statutory rate (Art. 104 CO) and reserve the right to claim further damages. C+C remains the owner of all delivered Products until receipt of full payment of the purchase price, including any shipping or ancillary costs.
Delivery dates or periods indicated by C+C are non-binding unless expressly confirmed in writing. C+C shall inform the Customer promptly of any foreseeable delay. Unless otherwise agreed in writing, delivery shall be made to the address specified by the Customer at the time of order. For commissioned works, unless otherwise agreed in writing, delivery shall be deemed complete once C+C has notified the Customer that the work is ready for collection or shipment. If the Customer fails to provide necessary delivery information in a timely manner prior to the delivery date, C+C reserves the right to store Products at cost and risk for the Customer. Partial deliveries are permitted and may be invoiced separately.
The risk of accidental loss or damage to the goods passes to the Customer only upon actual receipt of the goods. If the Customer is unable to take delivery at the agreed time through no fault of C+C, Section IX. Default of Delivery shall apply. Until delivery, the Products remain the property of C+C. Title to the Products transfers to the Customer only after full payment of the purchase price. If the Customer fails to provide necessary delivery information, risk transfers upon notification of readiness for dispatch.
Acceptance of goods For standard goods, acceptance shall be deemed to have occurred upon delivery to the Customer, provided that no obvious defects are reported within a reasonable time after receipt. This does not affect the Customer’s statutory warranty rights under Swiss law. Acceptance of Commissioned Works For commissioned or customised works, C+C shall notify the Customer when the work is complete and ready for delivery or collection. The Customer shall examine the work within a reasonable time and confirm acceptance if it substantially conforms to the agreed specifications and concept. Minor deviations in colour, form, or artistic interpretation that are inherent in the creative process do not constitute defects and do not justify refusal of acceptance. If the Customer fails to declare acceptance within a reasonable period after notification of completion, or if the Customer uses or pays for the work without reservation, the work shall be deemed accepted.
If the Customer refuses to take delivery of the goods or commissioned work without valid reason or fails to cooperate in accepting delivery at the agreed time, the Customer shall be deemed to be in default of acceptance (Annahmeverzug) in accordance with Articles 91 et seq. of the Swiss Code of Obligations. In such a case, C+C shall set a reasonable grace period in writing for the Customer to accept delivery. If the Customer does not accept delivery within this period, C+C may, at its discretion: (a) withdraw from the contract and claim compensation for any losses actually incurred (including additional transport, insurance, storage, or administrative costs); or (b) store the Products at the Customer’s expense and risk, either on its own premises or with a third party. Once the Customer is in default of acceptance, the risk of accidental loss or damage to the Products shall pass to the Customer, provided thatC+C has duly offered delivery. C+C shall inform the Customer in writing before exercising any of the above rights. This provision does not affect the Customer’s statutory warranty or withdrawal rights under Swiss law.
Ownership of the Products shall not pass to the Customer until C+C has received full payment of the purchase price and all related costs. C+C is entitled to register the retention of titlein the competent public register pursuant to Article 715 of the Swiss Civil Code (CC) at the Customer’s cost, until payment has been made in full. Until ownership has passed, the Customer shall handle the Products with due care and shall not sell, pledge, or otherwise dispose of them without C+C’s prior written consent.
The Customer may not offset counterclaims or withhold payments unless such counterclaims are undisputed or have been confirmed by a final court judgment. This does not affect the Customer’s statutory rights in the event of defects or non-performance.
All intellectual property rights in the Products, including but not limited to copyrights, design rights, trademarks, and moral rights, remain the exclusive property of Philippe Cramer unless otherwise specifically stated. The Customer acquires only ownership of the physical object. Unless expressly agreed otherwise in writing, the purchase or commissioning of a work does not confer any rights to reproduce, distribute, publicly display, modify, or otherwise use the work or its image for commercial or promotional purposes. Any use of the goods or commissioned works beyond private, personal enjoyment – including reproduction, exhibition, publication, digital display, or commercial use – requires the prior written consent of Philippe Cramer. The Customer shall not remove, alter, or obscure any signature, logo, or copyright notice appearing on the Products or its packaging. In the event of unauthorised use, reproduction, or modification, C+Cand/or Philippe Cramer reserves the right to seek appropriate legal remedies and damages under Swiss intellectual property law. This provision applies equally to both original artworks and design objects, as well as to any commissioned or customised works created under these Terms.

Warranty for Goods and Commissioned Works
For goods,for which C+C has not explicitly indicated an exclusion of warranty (e.g. heritage, used, refurbished and/or repurposed goods and other items sold “as is” or otherwise)C+C warrants that they are authentic and free from material defects at the time of delivery. Any further warranty, in particular for the long-term condition of the materials or suitability for a particular purpose, is excluded to the extent permitted by law.
For commissioned works, C+C warrants that the work corresponds to the agreed concept, design, and specifications at the time of delivery.
With respect to the goods and commissioned works, C+C shall not be liable for minor variations in colour, form, or surface structure that are inherent to the creative process, or subjective aesthetic preferences or artistic interpretation.
Scope and Duration of Warranty
In the event of a defect, C+C shall, at its discretion, repair the defect, replace the defective item, or refund the purchase price. Slight variations in colour, form, or artistic expression compared with descriptions, images, or sketches do not constitute defects.
The warranty does not cover normal wear and tear, damage caused by improper handling, installation, or use contrary to C+C’s instructions, or modifications made by the Customer or third parties.
The warranty period shall be two (2) years from the date of delivery of the goods or completion of the commissioned work, unless mandatory Swiss law provides a longer period.
The Customer’s mandatory rights under Swiss law, including those arising under Articles 197 et seq. and 367 et seq. of the Swiss Code of Obligations, as well as the Swiss Product Liability Act (PrHG), remain unaffected.
Customer Responsibility
The Customer shall use the Products with due care and in accordance with C+C’s instructions. C+C shall not be liable for damages resulting from misuse, improper installation, or modification of the Products by the Customer or third parties.
This clause does not affect the Customer’s statutory rights under Swiss law, including rights arising from defective goods or works under Articles 197 et seq. and 367 et seq. of the Swiss Code of Obligations or from the Swiss Product Liability Act (PrHG).
Liability
C+C shall be liable for damages caused intentionally (Vorsatz) or through gross negligence (grobeFahrlässigkeit).
C+C’s liability for damages caused by ordinary negligence shall be limited to the foreseeable damages typical for such transactions and shall in no event exceed purchase price of the Products or services concerned. This limitation does not apply to damages caused by wilful misconduct, gross negligence, or to injury to life, body or health, or to statutory warranty rights.
C+C shall not be liable for any indirect or consequential damages, such as loss of profit, loss of enjoyment, or loss of data, except where mandatory Swiss law provides otherwise.
Nothing in these Terms shall exclude or limit the Customer’s statutory rights under Swiss law, including rights arising from defective goods or works under Articles 197 et seq. and 367 et seq. of the Swiss Code of Obligations or from the Swiss Product Liability Act (PrHG), nor any liability for death or personal injury.

C+C processes personal data of the Customer in accordance with the applicable data-protection legislation, in particular the Swiss Federal Data Protection Act (FADP) and, where applicable, the EU General Data Protection Regulation (GDPR).
The nature, purpose, and scope of the personal data collected and processed in connection with the order, delivery, and customer relationship are described in C+C’s Data Protection Policy, which forms an integral part of these Terms.
The current version of the Data Protection Policy is available on C+C’s website at https://www.philippecramer.com/DataProtectionPolicy or will be provided to the Customer upon request.
By placing an order or entering into a contractual relationship with C+C, the Customer acknowledges having taken note of the Data Protection Policy.
For any questions regarding data protection or the exercise of rights relating to personal data, the Customer may contact C+C at the address or email specified in the Data Protection Policy.

C+C shall not be liable for any failure or delay in the performance of its obligations caused by events beyond its reasonable control, including but not limited to natural disasters, fire, flood, pandemic, war, terrorism, strikes, lockouts, transport or supply-chain disruptions, power failures, or governmental actions. If such circumstances prevent or delay delivery, C+C shall inform the Customer as soon as reasonably possible. The delivery period shall be extended by the duration of the event plus a reasonable start-up period. If the event continues for more than 60 days, either party may withdraw from the contract without liability, provided that no delivery has yet taken place. Any payments already made for undelivered Products or unperformed services shall be refunded.
These Terms will be governed by and construed in accordance with Swiss law,to the exclusion of its conflict-of-law rules and the United Nations Convention on Contracts for the International Sale of Goods (CISG). Any disputes arising out of or in connection with these Terms or the contractual relationship will be subject to the exclusive jurisdiction of the courts of Geneva, Switzerland. For consumers with domicile in Switzerland, mandatory provisions on jurisdiction and consumer protection (in particular Art. 32 CO) remain unaffected; the Customer may also bring claims before the courts of their domicile.
Should any provision of these Terms be or become invalid or unenforceable, the remaining provisions shall remain in full force and effect. The invalid provision shall be replaced by a valid one that most closely reflects the economic intent and purpose of the original. C+C reserves the right to amend these Terms at any time. The version in effect at the time the Customer places the order shall apply. Changes will be published on C+C’s website or communicated to the Customer in writing where appropriate.

For questions, complaints, warranty claims, or data-protection matters, the Customer may contact C+C at:
Cramer + Cramer Sàrl
Address: 8 rue de la Muse, CH – 1205 Geneva.
Tel.: +41 22 321 48 12
E-mail: info@philippecramer.com
Website: www.philippecramer.com

B2B General Terms & Conditions (2025.12.06)

These General Terms and Conditions (“Terms”) apply to all sale of goodscommission of works and provision of services agreements betweenCramer + CramerSàrl (“C+C”) to business customers, including companies, legal entities, public institutions, and sole traders (collectively “Customer”). They govern the formation, content, and performance of contracts for the sale of artworks, design objects, and customized or commissioned works, whether concluded in person, by correspondence, or via C+C’s website or other electronic means. Any general terms and conditions of the Customer are excluded, even if not expressly rejected. Individual written agreements between C+C and the Customer shall prevail over these Terms. By placing an order or entering into a business relationship with C+C, the Customer acknowledges and accepts these Terms in their current version. C+C reserves the right to amend the Terms at any time; the version in effect at the time of order placement shall apply.
Product and service descriptions, catalogues, brochures, price lists, and online listings are non-binding invitations to place an order and do not constitute legally binding offers. The Customer’s order constitutes an offer to purchase. A contract is formed only when C+C confirms acceptance in writing (including by email) or by dispatching or delivering the goods or commissioned work. C+C reserves the right to refuse orders, in particular for limited editions, made-to-order works, or where payment reliability cannot be verified. For commissioned works, the scope, concept, and specifications shall be set out in a written confirmation or project brief approved by both parties before work commences.

The Customer acknowledges that all goods and commissioned works (the “Products”) are artistic creations. Their artistic value takes precedence over functional characteristics. Minor deviations in color, form, surface, or artistic expression are inherent to the creative process and do not constitute defects.
Natural variations in materials (e.g., glass, wood, ceramics, metal, stone) are normal. Fading, cracking, patina, or dimensional changes caused by environmental factors such as humidity or light are not defects.
C+C strives to ensure accuracy of descriptions and images, but deviations from catalogues, digital representations, or prototypes shall not give rise to any claim, unless expressly guaranteed in writing.

Prices are in CHF and exclusive of Swiss VAT, unless otherwise indicated. Handling, packaging, shipping, insurance, storage and other incidental costs are charged separately. For cross-border transactions, the Customer bears all customs duties, import taxes, and administrative fees. C+C may adjust prices to reflect changes in taxes, import duties, or other public charges occurring after order placement but before delivery.
Unless otherwise agreed, payment is due in advance or within 10 days from the invoice date without deduction. Late payments accrue interest at the statutory rate (Art. 104 CO). C+C retains ownership of all Products until full payment has been received. In the event of non-payment, C+C may reclaim the goods and recover costs associated with retrieval.
Delivery dates are non-binding unless expressly confirmed in writing. For all purchases destined for international shipping, deliveries will only be affected upon receipt by C+Cof fullpayment from Customer. Risk of loss or damage passes to the Customer upon handover to the carrier (FCA C+C workshop, Geneva, Incoterms® 2020). If the Customer delays acceptance or fails to provide necessary delivery information, risk transfers upon notification of readiness for dispatch. Partial deliveries are permitted and may be invoiced separately.

The Customer shall inspect the goods immediately upon receipt and notify C+C in writing of any defects within five (5) business days of delivery. After this period, the goods are deemed accepted and free from defects.

For commissioned works, the Customer shall confirm acceptance upon completion and delivery. If no written objection is raised within ten (10) days, or if the work is used or installed, it shall be deemed accepted.

If the Customer is in default of payment or fails to timely accept delivery or performance (including commissioned works), C+C is entitled – without prejudice to any other rights or remedies – to store the goods and/or commissioned works at the Customer’s cost and risk. Storage may occur at C+C’s premises or at a third-party facility chosen at C+C’s discretion. All costs associated with storage, including but not limited to storage fees, insurance, handling, transport, and administrative charges, shall be borne by the Customer. As of the time the Customer falls into default of acceptance or payment, risk of loss, damage, deterioration, theft, or destruction of the goods and/or commissioned works shall pass to the Customer, irrespective of whether storage occurs at C+C’s or a third-party location. C+C may, after giving the Customer a written grace period of at least 10 days, dispose of the stored goods and/or commissioned works in an appropriate manner and claim damages for any losses incurred, including the difference between the contract price and the proceeds of such disposal. C+C’s right to claim additional damages arising from the Customer’s delay – includinglost profit in the case of individually commissioned works – remains expressly reserved.
The Customer acknowledges that the Products supplied by C+C are artworks, design objects, or individually produced creative works whose artistic character predominates over any functional aspect. To the fullest extent permitted by Swiss law, C+C hereby excludes any and all warranties and liability for defects within the meaning of Articles 197 et seq. and 368 et seq. of the Swiss Code of Obligations (CO), whether statutory or otherwise. In particular, C+C provides no warranty that the Products:  are free from material or manufacturing imperfections, especially those inherent to artistic, artisanal or handcrafted production,  meet any technical, aesthetic, or functional expectation of the Customer, or  will maintain their form, color, or surface characteristics over time. Minor deviations in color, texture, form, or artistic interpretation are inherent to the creative process and do not constitute defects. The only warranty retained is that each artwork, design object, or commissioned work is authentic and created by or under the supervision of the artist or designer identified as its author at the time of delivery. The Customer expressly waives all rights and remedies arising from any other defect, including rights of rectification, rescission, reduction of price, or damages under Articles 197 et seq. or 368 et seq. CO. This exclusion shall not apply where C+C has fraudulently concealed a defect within the meaning of Article 199 CO. Any statements, descriptions, sketches, or images provided by C+C, whether in catalogues, online, or in communications, are for informational purposes only and shall not be deemed guarantees of characteristics within the meaning of Article 197 CO unless expressly confirmed in writing as such by C+C.
C+C shall be liable only for damages resulting from its willful misconduct or gross negligence. Any liability for slight or ordinary negligence is hereby excluded to the maximum extent permitted by law. To the fullest extent permitted by applicable law, C+C’s total aggregate liability for any and all claims, losses, damages, or costs arising out of or in connection with the contract, the Products, or the services (whether in contract, tort, or otherwise) shall be limited to the net purchase price actually paid by the Customer for the specific Product or service giving rise to the claim. C+C shall in no event be liable for any indirect, incidental, punitive, exemplary, special or consequential damages, including but not limited to loss of profit, loss of revenue, business interruption, loss of use, loss of data, loss of anticipated savings, reputational harm, or third-party claims, except to the extent liability cannot be excluded by mandatory law. The Customer acknowledges that the Products are objects of art, often unique, artisanaland/or handcrafted, and may require careful handling, installation, and ongoing care. C+C assumes no liability for damage resulting from improper handling, installation, mounting, positioning, display, storage, environmental conditions, transport, cleaning or maintenance, or from any use contrary to C+C’s instructions or warnings. Nothing in this clause shall exclude or limit liability where such exclusion or limitation is prohibited under mandatory Swiss law, including for death or personal injury caused by willful misconduct or gross negligence.

The Customer shall indemnify, defend, and hold harmless C+C, its directors, officers, employees, subcontractors, and agents from and against any and all claims, liabilities, damages, losses, fines, penalties, and expenses (including reasonable legal and professional fees) arising out of or in connection with:

  1. the installation, handling, use, storage, display, or transportation of any Product after delivery;
  2. any breach of contract, negligence, or omission by the Customer or its agents, contractors, or employees;
  3. any third-party claim relating to property damage, personal injury, or other loss arising from or in connection with the Customer’s use of the Products; and
  4. any unauthorized reproduction, modification, or public presentation of artworks or commissioned works.

This obligation to indemnify and hold harmless shall apply regardless of whether the damage or claim arises on the Customer’s premises or at a third-party site, and whether the work was installed by the Customer, C+C, or a third party acting on the Customer’s behalf.

The Customer’s duty to indemnify does not apply to the extent that the damage was caused by C+C’s willful misconduct or gross negligence.

In the case of commissioned installations, site-specific works, or public artworks (collectively, “Installations”), the Customer assumes full responsibility for the installation environment and related safety conditions.

The Customer shall indemnify, defend, and hold harmless C+C, its affiliates, officers, employees, subcontractors, and agents against all claims, liabilities, damages, and costs (including legal fees) arising out of or in connection with:

  1. the installation, assembly, anchoring, or structural integration of any Installation on or within a building, landscape, or public space;
  2. accidents, injuries, or property damage occurring during or after installation, including due to environmental exposure, public interaction, or insufficient maintenance;
  3. permits, safety certifications, or municipal approvals required for the Installation; and
  4. any third-party claims brought by property owners, contractors, visitors, or public authorities relating to the Installation.

The Customer is solely responsible for:

  • ensuring that site conditions, foundations, fixtures, and environmental factors are suitable for the Installation;
  • securing and maintaining adequate insurance coverage (including general liability and property insurance) for installation, public display, and ongoing maintenance; and
  • ensuring that any third-party installers, engineers, or contractors act in full compliance with applicable safety, construction, and public-law regulations.

C+C shall not be liable for any damage, loss, or injury arising from on-site activities, structural failure, vandalism, weather exposure, or interaction with the public, except in cases of willful misconduct or gross negligence.
The Customer’s indemnification obligations shall survive delivery, acceptance, and installation, and remain in force for the duration of the Installation’s presence at the site.

The Customer may not offset counterclaims or withhold payments unless such counterclaims are undisputed or have been confirmed by a final court judgment. This does not affect the Customer’s statutory rights in the event of defects or non-performance.
All intellectual property rights, including but not limited to copyrights, design rights, trademarks, and moral rights, remain the exclusive property of Philippe Cramer. The Customer acquires ownership only of the physical object. No rights of reproduction, distribution, exhibition, or modification or otherwise to use the Product or its image for commercial or promotional purposesare transferred without Philippe Cramer’s prior written consent. The Customer shall not remove, alter, or obscure any signature, logo, or copyright notice appearing on the Products or their packaging. Unauthorized use may give rise to damages and injunctive relief under Swiss or any other applicable intellectual property law. This provision applies equally to both original artworks and design objects, as well as to any commissioned or customized works created under these Terms.
Ownership of the Products remains with C+C until full payment is received. C+C may register the retention of title under Art. 715 CC at the Customer’s cost. Until ownership passes, the Customer shall store the Products carefully and insure them at replacement value.
C+C shall not be liable for non-performance or delay due to events beyond its reasonable control, including force majeure, natural disasters, war, strikes, pandemics, transportation damage or supply-chain disruptions. If such events last more than 60 days, C+C may withdraw from the contract without liability for undelivered goods.

C+C processes business partner data in compliance with the Swiss Federal Data Protection Act (FADP) and, where applicable, the EU General Data Protection Regulation (GDPR). Details are set out in C+C’s Data Protection Policy available on its website at https://www.philippecramer.com/DataProtectionPolicy.

By placing an order or entering into a contractual relationship with C+C, the Customer acknowledges having taken note of the Data Protection Policy.
For any questions regarding data protection or the exercise of rights relating to personal data, the Customer may contact C+C at the address or email specified in the Data Protection Policy.

These Terms and any contract between the parties shall be governed by Swiss substantive law, excluding conflict-of-law rules and the CISG. The exclusive place of jurisdiction shall be Geneva, Switzerland.
If any provision of these Terms is or becomes invalid, the remaining provisions remain valid. The invalid clause shall be replaced by a valid one closest in meaning and purpose. C+C may amend these Terms at any time. The valid version at the time of contract formation applies.

Cramer + Cramer Sàrl
Address: 8 rue de la Muse, CH – 1205 Geneva.
Tel.: +41 22 321 48 12
E-mail: info@philippecramer.com
Website: https://www.philippecramer.com

All products, artworks, designs thereof and derivative works thereof are the sole property of their author Philippe Cramer. These products, artworks, designs and any derivative works thereof may not be used in any way without the prior written consent of the author. All and any copies, adaptations or interpretations of these designs are subject to the same copyright laws.
Click & Drag